Low-Cost Urban Road Safety Program 2025-26 Package 4A: Asphalt Treatments and Associated Works
| Tender name | Low-Cost Urban Road Safety Program 2025-26 Package 4A: Asphalt Treatments and Associated Works |
| Tender number | RFT 30-2025 |
| Advertisement date and time | March 28, 2026 12:00 AM |
| Closing date and time | April 24, 2026 02:00 PM |
| Description | To improve the safety of roads for local communities, the State Government implemented the Low-Cost Urban Road Safety Program (“LCURS”). The program delivers treatments to local roads, on an area-wide or whole-of-street basis, to reduce crash risks for drivers and vulnerable road users, such as pedestrians and cyclists. While there are a number of proposed precincts for these safety treatments within the City of Bayswater, this Request covers Package 4A of Maylands Peninsula Precinct. The City is seeking the services of suitably experienced contractor/s to undertake the Works including relevant approvals. It is proposed that this Contract will be awarded to one contractor. The Works for Package 4A is expected to achieve Practical Completion no later than 30 June 2026. Respondents are required to submit a detailed construction program for the Works. |
| Advertisement notice | Advert.pdf |
| Opened in the presence of | Sheldon Cox and Victor Popescu |
| List of tender submissions | BOS Civil Pty Ltd Roads 2000 Pty Ltd SGA Roads Pty Ltd WCP CIVIL PTY LTD |
| Winning tender name | WCP CIVIL PTY LTD |
| Their consideration | As per schedule of rates |
| Report recommendation date / Date of approval | June 17, 2026 |
Back to tenders